Terms of Service

1. Acceptance of Terms

By engaging Customized Bar ("we," "our," or "us") for hospitality design services or using our website, you agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our services.

2. Services Description

Customized Bar provides hospitality venue design services including:

• Narrative-driven concept development
• Bespoke fabrication and installation
• Digital and immersive experience layers
• Project management and coordination
• Opening support and operational guidance

3. Project Engagement

• All projects begin with a discovery phase and formal proposal
• Work commences upon signed agreement and deposit
• Project timelines are estimates and may vary based on scope
• Changes to scope may require revised timelines and pricing

4. Payment Terms

• Deposits are required to secure project scheduling
• Payment milestones are outlined in each project proposal
• All fees are in the currency specified in the proposal
• Late payments may result in project delays
• Custom fabrication deposits are non-refundable once production begins

5. Intellectual Property

All designs, concepts, and creative materials produced by Customized Bar remain our intellectual property until full payment is received. Upon full payment, you receive a license to use the designs for the specified venue.

We retain the right to photograph and document projects for our portfolio with appropriate credit.

6. Client Responsibilities

• Provide accurate venue specifications and requirements
• Secure necessary permits and approvals
• Provide timely feedback and approvals
• Ensure site readiness for installation
• Comply with local building and safety codes

7. Warranties

We warrant that our design services will be performed with professional skill and care. Custom fabrication includes a 12-month warranty against defects in materials and workmanship under normal use.

8. Limitation of Liability

TO THE MAXIMUM EXTENT PERMITTED BY LAW, CUSTOMIZED BAR SHALL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, OR PUNITIVE DAMAGES. OUR TOTAL LIABILITY SHALL NOT EXCEED THE FEES PAID FOR THE SPECIFIC PROJECT.

9. Termination

Either party may terminate a project with written notice. Upon termination, you are responsible for payment of all work completed and committed expenses. Deposits for custom fabrication may be non-refundable.

10. Governing Law

These Terms shall be governed by the laws of Argentina. Any disputes shall be resolved through good-faith negotiation or, if necessary, through the courts of Buenos Aires.

11. Contact

For questions about these Terms, contact us at:

Email: [email protected]

Phone: +54 9 11 3868-7797